Effective Date: 01/01/2026 – 01/01/2027
Welcome to WLine Property & Site Services. By accessing, browsing, or using this website, requesting information, submitting forms, requesting estimates, or engaging our services, you agree to be bound by these Terms and Conditions.
1. Website Use
The information provided on this website is for general informational purposes only. WLine reserves the right to modify, update, suspend, or remove any content, services, or website features without prior notice.
The content of this website shall not be interpreted as a binding offer, guarantee, warranty, or contractual commitment.
2. Estimates, Quotes & Proposals
All estimates, proposals, budgets, pricing, schedules, and project information provided by WLine are preliminary unless incorporated into a separate written agreement.
Prices may be adjusted due to:
- Changes in project scope
- Additional work requests
- Site conditions
- Material availability
- Project delays
- Customer modifications
- Safety requirements
- Access restrictions
No pricing shall be considered final until accepted in writing by both parties.
3. Scope of Work
WLine performs services only as specifically outlined in approved proposals, work orders, contracts, or written agreements.
Any work requested outside the approved scope may be subject to additional charges.
WLine reserves the right to decline work that presents safety concerns, hazardous conditions, structural issues, environmental risks, or conditions beyond the originally agreed scope.
4. Construction Cleaning Services
Construction cleaning services are intended to remove construction-related dust, debris, and residue within the agreed scope.
WLine shall not be responsible for:
- Existing property damage
- Construction defects
- Paint defects
- Flooring defects
- Improper installations by others
- Damaged finishes
- Material failures
- Water intrusion
- Mold
- Structural issues
- Damage caused by other trades
Clients are responsible for identifying pre-existing conditions before work begins.
5. Millwork, Fixture & Installation Services
WLine provides installation services based on materials supplied by clients, contractors, manufacturers, or third parties unless otherwise agreed in writing.
WLine is not responsible for:
- Manufacturing defects
- Design errors
- Missing components
- Incorrect measurements provided by others
- Material failures
- Product warranty claims
- Hidden site conditions
- Structural deficiencies
Clients shall verify all materials, dimensions, drawings, and specifications before installation begins.
6. Project Delays
WLine shall not be liable for delays caused by:
- Weather conditions
- Site readiness
- Material shortages
- Labor shortages
- Utility interruptions
- Acts of God
- Government actions
- Third-party contractors
- Owner delays
- Access restrictions
Project schedules are estimates only and are not guaranteed unless expressly stated in a written agreement.
7. Limitation of Liability
To the fullest extent permitted by law, WLine Property & Site Services shall not be liable for:
- Indirect damages
- Consequential damages
- Lost profits
- Lost business opportunities
- Project delays
- Business interruption
- Special damages
- Incidental damages
WLine’s maximum liability shall not exceed the amount paid directly to WLine for the specific services giving rise to the claim.
8. Customer Responsibilities
Customers agree to:
- Provide safe site access
- Ensure utilities are available when required
- Remove valuables and sensitive items
- Disclose known hazards
- Verify site readiness
- Review completed work promptly
Failure to provide reasonable access or safe working conditions may result in project delays or additional charges.
9. Independent Contractors & Subcontractors
WLine may utilize employees, subcontractors, independent contractors, or specialty service providers to perform portions of the work.
WLine reserves the right to determine staffing, scheduling, supervision, and project execution methods.
10. Intellectual Property
All website content, logos, branding, graphics, photographs, text, designs, proposals, marketing materials, and documents remain the property of WLine Property & Site Services.
No material may be copied, reproduced, distributed, or used without prior written consent.
11. Third-Party Links
This website may contain links to third-party websites. WLine is not responsible for the content, privacy practices, or operations of external websites.
12. No Warranty
Except where specifically provided in a separate written agreement, all services and website content are provided “as is” and “as available” without warranties of any kind, express or implied.
13. Governing Law
These Terms and Conditions shall be governed by and interpreted in accordance with the laws of the State of Texas.
Any dispute arising from the use of this website or WLine services shall be subject to the exclusive jurisdiction of the courts located in Texas.
14. Changes to Terms
WLine reserves the right to modify these Terms and Conditions at any time without prior notice. Continued use of the website constitutes acceptance of any revisions.
Contact Information
WLine Property & Site Services
Email: info@wlineconstruction.com
Dallas–Fort Worth, Texas